Works Restricted Procedure Notice |
| SECTION I: CONTRACTING AUTHORITY |
|---|
I.1) NAME, ADDRESSES AND CONTACT POINT(S) Official name: London Borough of Richmond upon Thames, Postal Address: Civic Centre, 44 York Street, Town: Twickenham, Telephone: 020 8891 7465, E-mail: r.rollison@richmond.gov.uk, Contact Point(s): , For the attention of: Richard Rollison, Postal Code: TW1 3BZ, Country: UNITED KINGDOM, Fax: 020 8891 7714, General address of the contracting authority (URL): www.richmond.gov.uk, Address of the Buyer Profile (URL): http://richmond.g2b.info/index.htm
I.1.1) Further information can be obtained at As in I.1.
I.1.2) Specifications and additional documents (including documents for a Dynamic Purchasing System) can be obtained at As in I.1.
I.1.3) Tenders or requests to participate must be sent to
I.2.1) Type of contracting authority Regional or local authority
If 'other' please specify
I.2.2) Main activity or activities
General Public Services
Environment
Recreation, culture and religion
Education
If 'other' please specify
I.2.2) The contracting authority is purchasing on behalf of other contracting authorities? No
| SECTION II: OBJECT OF THE CONTRACT |
|---|
II.1) DESCRIPTION
II.1.1) Title attributed to the contract by the contracting authority UK-Twickenham: Various Primary School Expansions-Construction Contracts
II.1.2) Type of contract and location of works, place of delivery or of performance Design and execution
II.1.2.1) Main Site or location of works London Borough of Richmond upon Thames Outer London - South
NUTS Code UKI22.
II.1.3) The notice involves A public contract
II.1.4) Information on framework agreement (if appropriate)
Number
OR, if applicable, maximum number of participants to the framework agreement envisaged
II.1.4.1) Duration of the framework agreement (if appropriate)
Period in year(s)
OR month(s)
Justification for a framework agreement the duration of which exceeds four years
II.1.4.2) Estimated total value of purchases for the entire duration of the framework agreement (give figures only)
Estimated value excluding VAT
OR range: between
and
Currency
Frequency and value of the contracts to be awarded (if possible)
II.1.5) Short Description of the contract or purchase(s) The construction of new building extensions, remodelling and refurbishment at Chase Bridge Primary School, Twickenham and Stanley Primary School, Teddington Construction work for buildings relating to education and research.Primary school construction work.Construction work for school buildings.
II.1.6) Common Procurement Vocabulary (CPV)
Main Object: 45214000.
Additional Object: 45214200.
Additional Object: 45214210.
II.1.7) Contract covered by the Government Procurement Agreement (GPA)? No
II.1.8) Division into lots Yes
If yes, tenders should be submitted for one or more lots
Lot No
ANNEX B - INFORMATION ABOUT LOTS
LOT No. 1
Title: UK-Twickenham: Various Primary School Expansions - Construction Contracts
1) Short Description: The construction of new building extensions, remodelling and refurbishment at Chase Bridge Primary School, Twickenham Construction work for buildings relating to education and research.Primary school construction work.Construction work for school buildings.
2) Common Procurement Vocabulary (CPV): Main Object: 45214000. Additional Object: 45214200. Additional Object: 45214210.
3) Quantity or Scope: Design Work from the end of RIBA Workstage D and the complete construction
If known, estimated cost (excluding VAT): 4820000
OR range: between and
Currency: GBP
4) Indication about different date for duration of contracts or starting/completion date (if applicable)
Period in months: or days:
OR Starting 01/02/2011 / delivery 31/08/2012
5) Additional Information About lots:
ANNEX B - INFORMATION ABOUT LOTS
LOT No. 2
Title: UK-Twickenham: Various Primary School Expansions- Construction Contracts
1) Short Description: The construction of new building extensions, remodelling and refurbishment at Stanley Primary School, Teddington Construction work for buildings relating to education and research.Primary school construction work.Construction work for school buildings.
2) Common Procurement Vocabulary (CPV): Main Object: 45214000. Additional Object: 45214210. Additional Object: 45214200.
3) Quantity or Scope: Design Work from the end of RIBA Workstage D and the complete construction
If known, estimated cost (excluding VAT): 7100000
OR range: between and
Currency: GBP
4) Indication about different date for duration of contracts or starting/completion date (if applicable)
Period in months: or days:
OR Starting 01/04/2011 / delivery 31/01/2013
5) Additional Information About lots:
II 1.9) Variants will be accepted No
II.2) QUANTITY OR SCOPE OF THE CONTRACT
II.2.1) Total quantity or scope (including all lots and options, if applicable) Design Work from the end of RIBA Workstage D and the complete construction Stanley Primary 7100000GBP Chase Bridge Primary 4820000GBP
If known, estimated value excluding VAT (give figures only)
OR range: between
and
Currency
II.2.2) Options (if applicable)
If yes, description of these options
If known, provisional timetable for recourse to these options: Period in month(s)
or day(s) (from the award of the contract)
Number of possible renewals (if any):
or Range: between
and
II.3) DURATION OF THE CONTRACT OR TIME PERIOD FOR COMPLETION
Either: Period in months 24
And / or days
Or: Starting
And/or ending
| SECTION III: LEGAL, ECONOMIC, FINANCIAL AND TECHNICAL INFORMATION |
|---|
III.1) CONDITIONS RELATING TO THE CONTRACT
III.1.1) Deposits and guarantees required (if applicable) A Contract bond/parent company guarantee will be required from the sucessful contractor
III.1.2) Main financing conditions and payment arrangements and/or reference to the relevant provisions regulating them As per construction contract JCT Design and Build 2007 Rev 2
III.1.3) Legal form to be taken by the grouping of economic operators to whom the contract is to be awarded (if applicable)
Not Applicable
III.1.4) Other particular conditions to which performance of the contract is subject (if applicable) No
If yes, description of particular conditions
III.2) CONDITIONS FOR PARTICIPATION
III.2.1) Personal situation of economic operators, including requirements relating to enrolment on professional or trade registers
Any supplier may be disqualified who:
(a) is bankrupt or is being wound up, where his affairs are being administered by the court, where he has entered into an arrangement with creditors, where he has suspended business activities or is in any analogous situation arising from a similar procedure under national laws and regulations;
(b) is the subject of proceedings for a declaration of bankruptcy, for an order for compulsory winding up or administration by the court or of an arrangement with creditors or of any other similar proceedings under national laws and regulations;
(c) has been convicted by a judgment which has the force of res judicata in accordance with the legal provisions of the country of any offence concerning his professional conduct;
(d) has been guilty of grave professional misconduct proven by any means which the contracting authorities can demonstrate;
(e) has not fulfilled obligations relating to the payment of social security contributions in accordance with the legal provisions of the country in which he is established or with those of the country of the contracting authority;
(f) has not fulfilled obligations relating to the payment of taxes in accordance with the legal provisions of the country in which he is established or with those of the country of the contracting authority;
(g) is guilty of serious misrepresentation in supplying the information required under this Section or has not supplied such information;
(h) has been the subject of a conviction for participation in a criminal organisation, as defined in Article 2(1) of Council Joint Action 98/733/JHA;
(i) has been the subject of a conviction for corruption, as defined in Article 3 of the Council Act of 26 May 1972 and Article 3(1) of Council Joint Action 98/742/JHA3 respectively;
(j) has been the subject of a conviction for fraud within the meaning of Article 1 of the Convention relating to the protection of the financial interests of the European Communities;
(k) has been the subject of a conviction for money laundering, as defined in Article 1 of Council Directive 91/308/EEC of 10 June 1991 on prevention of the use of the financial system for the purpose of money laundering.
Information and formalities necessary for evaluating if requirements are met As specified in tender documents
III.2.2) Economic and financial capacity
(a) appropriate statements from banks or, where appropriate, evidence of relevant professional risk indemnity insurance;
(b) the presentation of balance-sheets or extracts from the balance-sheets, where publication of the balance-sheet is required under the law of the country in which the economic operator is established;
(c) a statement of the undertaking's overall turnover and, where appropriate, of turnover in the area covered by the contract for a maximum of the last three financial years available, depending on the date on which the undertaking was set up or the economic operator started trading, as far as the information on these turnovers is available.
Information and formalities necessary for evaluating if requirements are met (If applicable) As specified in tender documents
Minimum level(s) of standards possibly required (if applicable) As specified in tender documents
III.2.3) Technical capacity
(a) a list of the works carried out over the past five years, accompanied by certificates of satisfactory execution for the most important works. These certificates shall indicate the value, date and site of the works and shall specify whether they were carried out according to the rules of the trade and properly completed. Where appropriate, the competent authority shall submit these certificates to the contracting authority direct;
(b) a list of the principal deliveries effected or the main services provided in the past three years, with the sums, dates and recipients, whether public or private, involved. Evidence of delivery and services provided shall be given: - where the recipient was a contracting authority, in the form of certificates issued or countersigned by the competent authority, - where the recipient was a private purchaser, by the purchaser's certification or, failing this, simply by a declaration by the economic operator;
(c) an indication of the technicians or technical bodies involved, whether or not belonging directly to the economic operator's undertaking, especially those responsible for quality control and, in the case of public works contracts, those upon whom the contractor can call in order to carry out the work;
(d) a description of the technical facilities and measures used by the supplier or service provider for ensuring quality and the undertaking's study and research facilities;
(e) where the products or services to be supplied are complex or, exceptionally, are required for a special purpose, a check carried out by the contracting authorities or on their behalf by a competent official body of the country in which the supplier or service provider is established, subject to that body's agreement, on the production capacities of the supplier or the technical capacity of the service provider and, if necessary, on the means of study and research which are available to it and the quality control measures it will operate;
(f) the educational and professional qualifications of the service provider or contractor and/or those of the undertaking's managerial staff and, in particular, those of the person or persons responsible for providing the services or managing the work;
(g) for public works contracts and public services contracts, and only in appropriate cases, an indication of the environmental management measures that the economic operator will be able to apply when performing the contract;
(h) a statement of the average annual manpower of the service provider or contractor and the number of managerial staff for the last three years;
(i) a statement of the tools, plant or technical equipment available to the service provider or contractor for carrying out the contract;
(j) an indication of the proportion of the contract which the services provider intends possibly to subcontract;
(k) with regard to the products to be supplied: (i) samples, descriptions and/or photographs, the authenticity of which must be certified if the contracting authority so requests; (ii) certificates drawn up by official quality control institutes or agencies of recognised competence attesting the conformity of products clearly identified by references to specifications or standards.
Information and formalities necessary for evaluating if requirements are met (If applicable) As specified in tender documents
Minimum level(s) of standards possibly required (if applicable) As specified in tender documents
III.2.4) Reserved Contracts (if applicable) No
IV.1) TYPE OF PROCEDURE Restricted procedure.
IV.1.2) Limitations on the number of operators that will be invited to tender or to participate (when applicable)
Envisaged number of operators
Or Envisaged minimum number 5
and, if appropriate, maximum number 8
Objective criteria for choosing the limited number of candidates: As specified within further information to be issued with the Pre qualification questionnaire
IV.2) AWARD CRITERIA
IV.2.1) Award criteria (please tick the relevant box(es)) B) The most economically advantageous tender in terms of: B2) the criteria as stated in the specifications, in the invitation to tender or to negotiate or in the descriptive document.
IV.2.2) An electronic auction will be used No
If yes, additional information about electronic auction (if appropriate)
IV.3) ADMINISTRATIVE INFORMATION
IV.3.1 File reference number attributed by the contracting entity (if applicable)
IV.3.2) Previous publication concerning the same contract No
If yes:
IV.3.2.1) Notice number in OJ:
Of
IV.3.2.2) Other previous publications
Notice number in OJ:
Of
IV.3.3) Conditions for obtaining specifications and additional documents (except for a DPS)
Time-limit for receipt of requests for documents or for accessing documents 28/07/2010
Time: 14:00
Payable documents No
If yes, Price (give figures only):
Currency
Terms and method of payment
IV.3.4) Time limit for receipt of tenders or requests to participate
Date 04/08/2010
Time 14:00
IV.3.5) Date of dispatch of invitations to tender or to participate to selected candidates
IV.3.6) Language(s) in which tenders or requests to participate may be drawn up English
Other - third country
IV.3.8) Conditions for opening tenders
IV.3.8.1) Date, time and place
Date
Time
Place (if applicable)
IV.3.8.2) Persons authorised to be present at the opening of tenders (if applicable)
If yes, authorised persons
| SECTION VI: COMPLEMENTARY INFORMATION |
|---|
VI.1) THIS IS A RECURRENT PROCUREMENT (if applicable) No
If yes, estimated timing for further notices to be published:
VI.2) CONTRACT(S) RELATED TO A PROJECT AND / OR PROGRAMME FINANCED BY EU FUNDS No
If yes, reference to project(s) and / or programme(s)
VI.3) ADDITIONAL INFORMATION (if applicable) The contracting authority considers that this contract may be suitable for economic operators that are small or medium enterprises (SMEs). For the avoidance of doubt, the contracting authority confirms that no weight will be attached to this factor. GO reference: GO 10070508/01
VI.4) PROCEDURES FOR APPEAL
VI.4.1) Body responsible for appeal procedures
Body responsible for mediation procedures (if applicable)
VI.4.2) Lodging of appeals (please fill heading VI.4.2 OR if need be, heading VI.4.3)
Precise information on deadline(s) for lodging appeals:
VI.4.3) Service from which information about the lodging of appeals may be obtained
VI.5) DATE OF DISPATCH OF THIS NOTICE 05/07/2010
END OF NOTICE
|